{"data":{"id":"us/18-cfr-1308.24","jurisdiction":"us","citation":"18 CFR 1308.24","heading":"Undue delay in Contracting Officer's decision.","body":"(a) If there is an undue delay by a Contracting Officer in issuing a decision on a claim, the Contractor may request the Chairman to direct the Contracting Officer to issue a decision within a specified period of time.\n(b) A request under this section shall:\n(1) Be in writing;\n(2) State the date on which the claim was submitted to the Contracting Officer.\n(3) State the date suggested for issuance of a decision by the Contracting Officer.\n(c) TVA may reply to a motion under this section within 5 days after its receipt.\n(d) The Chairman shall issue a written decision on the request. If granted, the decision shall specify the date by which the Contracting Officer's decision is to be rendered, and a copy shall be served on the Contracting Officer.","path":["Title 18—Conservation of Power and Water Resources","CHAPTER XIII—TENNESSEE VALLEY AUTHORITY","PART 1308—CONTRACT DISPUTES","Subpart C—Board of Contract Appeals"],"source_url":"https://www.ecfr.gov/api/versioner/v1/full/2026-08-25/title-18.xml","current_through":"2026-08-25","vintage":"","retrieved_at":"2026-08-27T02:24:34Z","sha256":"c53ba036b62b1beef7c750879225ec5fa610ae25e5e33235663b857ec379062e","source_id":"us-cfr","stale":true,"prev":"us/18-cfr-1308.23","next":"us/18-cfr-1308.25"},"notice":"GroundRules: Original legal text. Not legal advice."}