{"data":{"id":"us/48-cfr-42.1302","jurisdiction":"us","citation":"48 CFR 42.1302","heading":"42.1302 Suspension of work.","body":"A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.","path":["Title 48—Federal Acquisition Regulations System","CHAPTER 1—FEDERAL ACQUISITION REGULATION","SUBCHAPTER G—CONTRACT MANAGEMENT","PART 42—CONTRACT ADMINISTRATION AND AUDIT SERVICES","Subpart 42.13—Suspension of Work, Stop-Work Orders, and Government Delay of Work"],"source_url":"https://www.ecfr.gov/api/versioner/v1/full/2026-08-25/title-48.xml","current_through":"2026-08-25","vintage":"","retrieved_at":"2026-08-27T02:26:29Z","sha256":"10ac28d89949100529b5ee44dd47fbebb17547e96fa8545e02e3beb41654ec8d","source_id":"us-cfr","stale":true,"prev":"us/48-cfr-42.1301","next":"us/48-cfr-42.1303"},"notice":"GroundRules: Original legal text. Not legal advice."}