{"data":{"id":"us/48-cfr-42.1305","jurisdiction":"us","citation":"48 CFR 42.1305","heading":"42.1305 Contract clauses.","body":"(a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.\n(b)(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.\n(2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its Alternate I.\n(c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial products. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial products.","path":["Title 48—Federal Acquisition Regulations System","CHAPTER 1—FEDERAL ACQUISITION REGULATION","SUBCHAPTER G—CONTRACT MANAGEMENT","PART 42—CONTRACT ADMINISTRATION AND AUDIT SERVICES","Subpart 42.13—Suspension of Work, Stop-Work Orders, and Government Delay of Work"],"source_url":"https://www.ecfr.gov/api/versioner/v1/full/2026-08-25/title-48.xml","current_through":"2026-08-25","vintage":"","retrieved_at":"2026-08-27T02:26:29Z","sha256":"874b7100181e408d68cf985a97fe1ce81c6b3d905c9ea8a21ae08d7ea76aaf50","source_id":"us-cfr","stale":true,"prev":"us/48-cfr-42.1304","next":"us/48-cfr-42.1500"},"notice":"GroundRules: Original legal text. Not legal advice."}