{"data":{"id":"us/48-cfr-832.111-70","jurisdiction":"us","citation":"48 CFR 832.111-70","heading":"832.111-70 VA contract clauses for non-commercial purchases.","body":"(a)(1) Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System—Critical Path Method (NAS-CPM).”\n(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.\n(b)(1) Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System—Critical Path Method (NAS-CPM).”\n(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.","path":["Title 48—Federal Acquisition Regulations System","CHAPTER 8—DEPARTMENT OF VETERANS AFFAIRS","SUBCHAPTER E—GENERAL CONTRACTING REQUIREMENTS","PART 832—CONTRACT FINANCING","Subpart 832.1—Non-Commercial Item Purchase Financing"],"source_url":"https://www.ecfr.gov/api/versioner/v1/full/2026-08-25/title-48.xml","current_through":"2026-08-25","vintage":"","retrieved_at":"2026-08-27T02:26:29Z","sha256":"c1e8cf0e75fa21acf78696d9b255f6326c15e44a84aa0407e722e757d44367a6","source_id":"us-cfr","stale":true,"prev":"us/48-cfr-832.111","next":"us/48-cfr-832.202"},"notice":"GroundRules: Original legal text. Not legal advice."}