KRS 26A.168: Reports on status of court facilities projects and contingency fund.

(1) The Administrative Office of the Courts shall provide to the Capital Projects and

Bond Oversight Committee, at the committee's January, April, July, and October

regular meetings, a status report of all incomplete court facilities projects. The

Capital Proj ects and Bond Oversight Committee shall prescribe data elements for

the quarterly status reports. For each project, the status report shall include:

(a) The project title;

(b) The county in which the project is located;

(c) The scope and use allowance auth orized for the project in the judicial branch

budget, and any increases to the scope or use allowance under KRS 26A.164;

(d) The current status of the project;

(e) Estimated completion date of the project;

(f) An explanation of any delay or major change in the project, including deletion

or modification of project components; and

(g) Any other information that the committee requests.

(2) On August 1 of each year, the Administrative Office of the Courts shall prepare a

financial report on the court facility use allowance contingency fund for the fiscal

year ending on June 30 of that year. The report shall include, with explanations,

allotments, expenditures, encumbrances, and the available balance.