KRS 371.405: Conditions governing enforceability of construction contracts -- Payment

of amounts due.

(1) All payments on construction contracts entered into after June 26, 2007, shall be

made pursuant to the terms of the contract and as required in this section and KRS

371.410.

(2) The following provisions in a contract for construction shall be against the public

policy of this Commonwealth and shall be void and unenforceable:

(a) A provision that purports to waive, release, or extinguish the right to re solve

disputes through litigation in court or substantive or procedural rights in

connection with such litigation, except that a contract may require binding

arbitration as a substitute for litigation or require nonbinding alternative

dispute resolution as a prerequisite to litigation;

(b) A provision that purports to waive, release, or extinguish rights provided by

KRS Chapter 376, with the exception of partial waivers of lien rights provided

by the contractor or subcontractor for progress payments;

(c) A provision that purports to waive, release, or extinguish any of the

requirements of KRS 371.160; or

(d) A provision that purports to waive, release, or extinguish the right of a

contractor or subcontractor to recover costs, additional time, or damages, or

obtain an equitable adjustment of the contract, for delays in performing the

contract that are, in whole or part, within the control of the contracting entity.

Unusually bad weather that cannot be reasonably anticipated, fire, or other act

of God shall not automatically entitle the contractor to additional

compensation under this paragraph.

(3) Subsection (2)(d) of this section shall not render null, void, and unenforceable a

contract provision that:

(a) Permits a contractor or subcontractor to recover that portion of delay costs

caused by acts or omissions of the contracting entity;

(b) Requires notice of any delay by the party affected by the delay;

(c) Provides for reasonable liquidated damages;

(d) Provides for arbitration or any other procedure designed to resolve contract

disputes; or

(e) Specifies which costs are recoverable by a contractor or subcontractor for

delay.

(4) If a provision of a construction contract is found to be null and unenforcea ble, that

provision shall not affect other provisions of the contract that are in compliance

with this section and, to this end, the provisions of the contract are severable.

(5) Except as provided in subsection (7) of this section, all contracts for const ruction

shall provide that payment of amounts due a contractor from a contracting entity,

except retainage, shall be made within thirty (30) business days after the contracting

entity receives a timely, properly completed, undisputed request for payment.

(6) Except as provided in subsection (7) of this section, if the contracting entity fails to

pay a contractor within thirty (30) business days following receipt of a timely,

properly completed, undisputed request for payment, the contracting entity shall

pay interest to the contractor beginning on the thirty -first business day after receipt

of the request for payment, computed at the rate of twelve percent (12%) per annum

on the unpaid amount. Twenty -five (25) business days following the submission of

a timely, properly completed, undisputed request for payment, the contractor shall

notify the contracting entity by certified mail if payment has not been received. The

notice shall also include the date on which interest shall begin to accrue.

(7) For purposes of subsections (5) and (6) of this section, a postsecondary institution

and a board of education shall have forty -five (45) business days to make the

payment required by those subsections. For purposes of payments by a board of

education, the Department of Education shall have ten (10) business days, including

the day the undisputed request for payment is received, to complete the final

approval and application for payment and return it to the board of education. The

ten (10) business days shall be included in the forty -five (45) business days. If the

contracting entity fails to pay a contractor within forty -five (45) business days after

receipt of the timely, properly completed, undisputed request for payment, the

contracting entity shall, beginning on the forty-sixth day after receipt of the request,

pay interest to the contractor computed at the rate of twelve percent (12%) per

annum on the unpaid amount.

(8) A contractor shall pay its subcontractors any undisputed amounts due within fifteen

(15) business days of receipt of payment from the contracting entity, including

payment of retainage if retainage is released by the contracting entity, if the

subcontractor has provided a timely, properly completed, and undisputed request

for payment to the contractor.

(9) If a contractor fails to pay a subcontractor any undisputed amounts due within

fifteen (15) business days of receipt of payment from the contracting entity, the

contractor shall pay interest to the subcontractor beginning on the sixteenth

business day after receipt of payment by the contractor, computed at the rate of

twelve percent (12%) per annum on the unpaid amount.

(10) Subsections (8) and (9) of this section shall apply to all payments from

subcontractors to their subcontractors.