GroundRules
48 CFR 3452.242-71: 3452.242-71 Notice to the Government of delays.
Where this section sits in the code
- Title 48—Federal Acquisition Regulations System
- CHAPTER 34—DEPARTMENT OF EDUCATION ACQUISITION REGULATION
- SUBCHAPTER H—CLAUSES AND FORMS
- PART 3452—SOLICITATION PROVISIONS AND CONTRACT CLAUSES
- Subpart 3452.2—Text of Provisions and Clauses
As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:
Notice to the Government of Delays (MAR 2011)
The contractor shall notify the contracting officer of any actual or potential situation, including but not limited to labor disputes, that delays or threatens to delay the timely performance of work under this contract. The contractor shall immediately give written notice thereof, including all relevant information.
(End of clause)
Collected 2026-08-27T02:26:29Z. Source file · JSON