GroundRules
48 CFR 52.211-12: 52.211-12 Liquidated Damages—Construction.
Where this section sits in the code
- Title 48—Federal Acquisition Regulations System
- CHAPTER 1—FEDERAL ACQUISITION REGULATION
- SUBCHAPTER H—CLAUSES AND FORMS
- PART 52—SOLICITATION PROVISIONS AND CONTRACT CLAUSES
- Subpart 52.2—Text of Provisions and Clauses
As prescribed in 11.503(b), insert the following clause in solicitations and contracts:
Liquidated Damages—Construction (SEP 2000)
(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.
(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(End of clause)
Collected 2026-08-27T02:26:29Z. Source file · JSON