GroundRules
48 CFR 42.1302: 42.1302 Suspension of work.
Where this section sits in the code
- Title 48—Federal Acquisition Regulations System
- CHAPTER 1—FEDERAL ACQUISITION REGULATION
- SUBCHAPTER G—CONTRACT MANAGEMENT
- PART 42—CONTRACT ADMINISTRATION AND AUDIT SERVICES
- Subpart 42.13—Suspension of Work, Stop-Work Orders, and Government Delay of Work
A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.
Collected 2026-08-27T02:26:29Z. Source file · JSON