GroundRules
48 CFR 42.1305: 42.1305 Contract clauses.
Where this section sits in the code
- Title 48—Federal Acquisition Regulations System
- CHAPTER 1—FEDERAL ACQUISITION REGULATION
- SUBCHAPTER G—CONTRACT MANAGEMENT
- PART 42—CONTRACT ADMINISTRATION AND AUDIT SERVICES
- Subpart 42.13—Suspension of Work, Stop-Work Orders, and Government Delay of Work
(a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.
(b)(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.
(2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its Alternate I.
(c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial products. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial products.
Collected 2026-08-27T02:26:29Z. Source file · JSON